Business 2 Business Terms

B2B / Trade Term and Conditions

The Below Term and Conditions are intended for B2B /Trade Customers ONLY
Retail Customers should refer to the  Retail T&C

1. GENERAL (a) These conditions apply to all sales of goods by any branch, division or any member company of Hortons Portable Buildings Ltd (The Seller) and shall prevail over any other terms or conditions contained or referred to in the Buyer's order or in correspondence or elsewhere or implied by trade custom, practice or course of dealing unless such other terms or conditions are specifically agreed to in writing by the Seller. The Seller's agents shall not have authority to enlarge, vary or exclude any of these conditions. Any purported enlargement, variation or exclusion thereof shall be without effect unless specifically agreed to in writing by the Seller and the Buyer.
   (b) No terms or conditions of any main building contract or sub-contract
   shall affect these conditions whether or not the Seller has notice thereof.
   (c) The headings appearing above each condition are included for reference purposes only and shall not affect or limit the interpretation and effect of these conditions.
   A quotation by the Seller shall constitute an invitation to treat and not an offer. The Seller may withdraw or amend any quotation at any time prior to the Seller's acceptance of the Buyer's order
   Any estimates in respect of quantities needed or advice as to the suitability or fitness of any goods for any particular purpose given by the Seller or its servants or agents will be treated as without obligation or responsibility on the part of the Seller and the Buyer will be entirely responsible for ascertaining the quantities required and the suitability and fitness of the goods for their purpose

2. PRICE
   (a) Subject to sub-clause (d) hereof, the price payable for the goods sold shall be that contained in the Seller's current price list at the time of dispatch, notwithstanding that this may differ from the price stated in any quotation by the Seller, unless the price quoted was not a list price current at the time of the quotation.
   (b) The Seller reserves the right to make such alterations to its price list as it thinks fit.
   (c) Subject to sub-clause (d) hereof, if there is no list price for the goods sold, or if the price quoted was not a list price current at the time of the quotation, then the price to be paid shall be the price specified in the quotation provided that the order has been accepted within the period specified in the quotation.
   (d) In addition to having the right reserved by sub-clause (b) hereof, the Seller shall have the right at any time and without notice to revise the price payable for the goods sold to take account of increases in costs including (without limitation) costs of any goods or materials carriage labour or overheads the increase or imposition of any tax duty or other levy and any variation in exchange rate since the date of preparation of the current price list or (in cases falling within sub-clause (c) hereof) acceptance of the order .
   (e) Unless otherwise agreed by the Seller in writing all prices shall be deemed to be inclusive of Value Added Tax which shall be payable by the Buyer at the rate prevailing at the tax point. For orders to be invoiced and shipped within the UK 20% VAT is added. For any other destination within the EU we need your VAT Number and full company details to be exempt. If this information is not supplied 20% VAT is added to the order value.
   (f) Unless otherwise agreed by the Seller in writing the Seller reserves the right to charge the Buyer the cost of transportation of the goods to the destination requested by the Buyer.

3. TERMS OF PAYMENT
   (a) Credit accounts are not offered.
   (b) For all transactions, quotations shall be for payment as set out in our standard terms as determined by the type of product transacted, and can be by bank transfer, cheque or cash - no card payments are accepted. The seller will not process the order if payment is not paid with the order.
   (c) The Buyer shall not be entitled to withhold or set off payment of any amount due to the Seller under the terms hereof whether in respect of any claim by the Buyer in respect of goods supplied by the Seller or for any other reason which is contested or for which liability is not admitted by the Seller.
   (d) Without prejudice to the Seller's right to enforce payment, if the Buyer fails to make payment as herein before provided the Seller shall be entitled to charge for storage of the goods plus interest  on any balance outstanding from the date the same became due for payment at the rate for the time being payable on High Court judgement debts pursuant to section 17 of the Judgements Act 1838.
   (e) Interest shall become due and payable pursuant to the foregoing clauses notwithstanding the fact that a portion of the account be subject to any dispute or query.
   (f) If in the case of any sale involving more than one delivery default is made in payment on the due date the Seller shall have the right forthwith to suspend any further deliveries until payment, or by notice in writing to the Buyer to terminate the contract in its entirety whether or not the same is severable.
   (g) If at any time the Buyer (being an existing customer) being a company shall alter its constitution or being a sole trader or partnership shall become incorporated or amalgamated with others it shall be the duty of the Buyer to give prior written notice of the intended change (should the Buyer wish to continue buying the goods following any intended change). Continuance of trading with the amalgamated entity or commencement of trading with a new entity shall be in the sole discretion and only deemed undertaken by the Seller on a written acknowledgement and acceptance is issued by the Seller's Credit Controller, Director or Company Secretary.

4. DELIVERY
   (a) Delivery dates mentioned in any quotation or acceptance form or elsewhere are approximate only and not of any contractual effect and the Seller shall not be under any liability to the Buyer in respect of any failure to deliver on any particular date or dates, nor shall time be of the essence of any contract.
   (b) Where delivery to site is undertaken by the Seller it is on the understanding that there is a suitable road to the point on the site where delivery is requested. If no such road exists delivery will be made to the nearest point to which in the opinion of the Seller's driver deems it can safely proceed and unload.
   (c) All necessary labour and equipment required to unload materials properly shall be supplied by the Buyer and the Seller's drivers shall not be responsible for unloading.
   (d) If the Buyer refuses or fails to take delivery of goods tendered in accordance with the Contract the Seller shall be entitled to immediate payment in full for the goods so tendered. The Seller shall be entitled to store at the risk of the Buyer any goods of which the Buyer refuses or fails to take delivery and the Buyer shall in addition to the purchase price pay all costs of such storage and any additional cost or carriage incurred as a result of such refusal or failure.

5. RISK
   The risk in the goods shall pass to the Buyer upon delivery or collection.

6. TITLE OF GOODS
   Until the Seller has been paid in full the price of the goods and the cost of packaging together with any interest and Charges therein:-
   (i) Ownership of the goods shall remain in the Seller, and the Buyer shall hold the goods as bailiff fiduciary owner for the Seller.
   (ii) The Buyer has a right to sell and deliver the goods to third parties in the ordinary course of its business, acting towards such third parties as a principal and not as the Seller's agent, but it shall hold all proceeds of sale on trust for the Seller in a separate bank account, the Buyer hereby assigning to the Seller all rights and claims which the Buyer may have against its customers arising from such sales until full payment is made as aforesaid.
   (iii) The Buyer shall if required by the Seller store the goods in such a way as clearly to show the Seller's ownership of them.
   (iv) The Buyer shall notify the Seller immediately upon demand by the Seller of the place or places where the goods are situated.
   (v) The Buyer shall afford to the Seller access to the goods during all normal business hours whether they are upon land occupied or owned by the Buyer or its customers and the Buyer shall deliver the goods up to the Seller at its request and allow the Seller to remove the same. For this purpose the Buyer hereby grants an irrevocable right and licence to the Seller's servants or agents to enter upon the said land with or without vehicles during normal business hours.

7. SELLER'S LIABILITY
   (a) The Seller does not exclude liability for death or personal injury to the extent that it results from the negligence of the Seller, its servants or agents.
   (b) The Seller accepts any liability for any breach on its part of any undertaking as to title implied by section 12 of the Sale of Goods Act 1979 or by section 8 of the Supply of Goods (Implied Terms) Act 1973.
   (c) The Seller does not accept liability for shortages in quantities delivered unless the Buyer notifies the Seller of any claim for short delivery of the goods within 2 working days of the delivery to the Buyer or to the Buyer's instructions in such circumstances the Seller's liability shall be restricted to making good the shortage.
   (d) The Seller agrees to repair or replace free of charge any goods which, in the opinion of the Seller, are defective due to a manufacturing fault, but only if the same is reported to the Seller in writing accompanied by photographic evidence within 2 working days of delivery of the goods to the Buyer or the Buyer's order, but the Seller will not be responsible either for the cost of removing any defective goods from any place where they are installed or affixed (or for making good the said place after removal) or for the cost of installing or affixing in such place any repaired or replacement goods unless the same shall have been previously agreed in writing with a Director of the Seller. The buyer shall allow the seller a reasonble time to source the replacement parts which may need to be machined and sourced from abroad.
   (e) Save as aforesaid, all liability for any representations whether oral or in writing and all guarantees, conditions or warranties whether expressed or implied by statute, common law or otherwise is hereby excluded and the Seller shall not be liable for any loss (including consequential loss), damage or delay or expense of any kind whatsoever and howsoever caused (including by the negligence of the Seller its servants or agents).
   (f) Save as to the matters set out in (a) and (b) above, the Buyer acknowledges and agrees that he is able (if he so wishes) to insure against the risk of any loss (including consequential loss), damage or delay or expense of any kind whatsoever and howsoever caused (including by the negligence of the Seller its servants or agents).
   (g) If the Buyer is dealing as consumer as defined by section 12 of the Unfair Contract Terms Act 1977 the Seller does not exclude liability for obligations arising under sections 13, 14 and 15 of the Sale of Goods Act 1979 or under sections 9, 10 and 11 of the Supply of Goods (Implied Terms) Act 1973.
   (h) Where fine or especial tolerances are required in the goods supplied beyond those generally accepted in the building trade, no liability will attach to the Seller unless such fine tolerances are notified in writing to the Seller at the time of order and the Seller has acknowledged in writing that it is prepared to accept such order.
   (i) The Buyer shall indemnify the Seller against any liability which the latter may incur (whether as a result of or in connection with court proceedings or under the terms of a bona fide out of court settlement) as a result of a claim against the Seller under Part I of the Consumer Protection Act 1987 in respect of an alleged defect in the goods.

8. MEASURES
   The Seller shall have the option to supply all or any of the goods in either metric or imperial sizes in the nearest equivalent measure and goods may be charged in metric measure allowing for conversion.

9. IMAGES
   If the Seller is acting as an agent and reselling Hortons goods, any images supplied by Hortons remain the property of Hortons regardless of the watermark. The Seller shall immediately cease using said images at the request of Hortons. The Seller shall also immediately cease using these images if the Seller stops selling Hortons products.  

10. PACKAGING
    (a) A charge may be made by the Seller for packaging to cover the cost of labour and materials.
    (b) Crates and cases may be charged for but charges will be credited in full when returnable empties are returned to the Seller carriage paid and in good condition.
    (c) Pallets may be charged for but charges will be credited in full if returned to the Seller carriage paid in good condition within seven days of delivery. A charge may be made if damaged or retained for more than seven days.
    (d) Polythene packaging, wrapping or sacks will be non-returnable.
    (e) The buyer will be solely responsible for the disposal of any waste arising from the goods and will comply with applicable laws, regulations and waste management licences relating to such waste. The Buyer will indemnify the Seller against all costs, claims, liabilities and expenses incurred by Seller arising from or in connection with any breach by the buyer of this clause 11(e).

11. CANCELLATION OF ORDERS
    The Seller may in its sole discretion accept or reject the cancellation of any order once such order has been accepted by the Seller. The Seller will in no circumstances accept the cancellation of an order for goods which are to be specially made or obtained once such an order has been accepted by the Seller nor will any allowance be made in respect of such goods where they are subsequently returned. If the Seller does agree to the cancellation of an order, anything done by the Seller for the Buyer only has value for the Buyer, contracts can only be brought to an end with written agreement and the Buyer paying all costs deemed to have been incurred plus all profits that would have accrued to the Seller from the contract. On termination of any part of any contract, the Buyer will indemnify and hold the Seller harmless against all related losses, including loss of profits, costs, other expenses, and damages, whether direct or consequential, incurred by the Buyer and/or the Seller, and the Buyer will pay all bills on demand.

12. RETURN OF GOODS
    The Seller may in its sole discretion accept or reject the return of any goods which have been incorrectly ordered in the event that the Seller decides to accept the return of such goods, such acceptance shall be upon such terms as the Seller may determine and in particular the Seller reserves the right to charge for the carriage and handling of such goods.

13. INCORRECT GOODS

    If You receive incorrect Goods/Parts, You must contact Us immediately on 01403 888 222. We will offer You -

    (a) a refund of all costs (including the delivery cost) of the Goods/Parts

    (b) Or replacement of the incorrect Goods (assuming they are unused and "as new") with the correct Goods.

    We will advise You if there will be a manufacturing delay for Your replacement Goods. You can ask for a refund if the delay would inconvenience You. Should You choose to wait for replacement Goods/Parts, We will not pay any compensation against any claim for Your lost time, nor against any claim for cancellation of independent contractors that You may have employed and pre-booked.

    (c) Paints - You (or your painting contractor in your presence) MUST open the tins of paint to ensure the colour is correct BEFORE applying to the building. If the wrong colour has been supplied then We will exchange it for the correct colour free of charge. No refunds or compensation will be be given if the wrong colour of paint has been applied to Your building.2.

14. FORCE MAJEURE CLAUSE
    The Seller shall be under no liability for any loss (including consequential loss), damage, or delay or expense of any kind whatsoever caused wholly or in part by Act of God, outbreak of war, civil commotion, governmental policies or restrictions or control, including restrictions of export or import or other licences, trade or industrial disputes of whatever nature, whether or not such dispute involves the Seller, its servants or agents, or by any other contingency whatsoever which is beyond the control of the Seller.

15. BUYER'S BANKRUPTCY OR INSOLVENCY
    If the Buyer makes a proposal for or enters into a scheme of arrangement or a composition with his or its creditors or fails to comply with a statutory demand for the repayment of a debt within the time therein allowed, or if (where the Buyer is an individual or, where the Buyer is a partnership, in the case of any individual partner) an application is made to the court under Part VIII of the Insolvency Act 1986 for an interim order for the purpose of a voluntary arrangement or an order is made for the administration of his estate pursuant to Part VI of the County Courts Act 1984 or a bankruptcy petition relating to him is presented to the court, or he is adjudged bankrupt, or if (where the Buyer is a company) a petition for an administration order is presented to the court pursuant to Part II of the Insolvency Act 1985 or the Buyer passes a resolution or the court makes an order that it shall be wound up (otherwise than for the purpose of amalgamation or reconstruction) or a receiver or administrative receiver is appointed of any of the assets or undertaking of the Buyer or circumstances arise which entitle the court or a creditor to appoint a receiver or administrative receiver or (where the Buyer is either a company or a partnership) which entitle the court to make a winding-up order or (whether the Buyer is a company, a partnership or an individual) the Buyer takes or suffers any similar action in consequence of debt, the Seller may stop any goods in transit and suspend further deliveries and may forthwith determine the contract without prejudice to the continuation of all the Seller's rights hereunder and to any existing claims. Where goods have been delivered but not paid for, the price shall immediately become due and payable.

16. NON-WAIVER OF RIGHTS
    This failure by either party to the contract to exercise or enforce any rights conferred by the contract shall not be deemed to be a waiver of any such right nor operate so as to bar the exercise or enforcement thereof at any time or times thereafter.

17. NOTICES
    Any notices hereunder shall be in permanent readable form and shall be deemed properly delivered if addressed to that party concerned at its principal place of business or last known address.
    18. MEASUREMENTS AND SPECIFICATIONS
    The measurements in brochures, catalogues and promotional matter are approximate and are to give a rough idea of size and dimensions. The manufacturers reserve the right to change specifications without notice. 

18. PLANNING

    (a) You must ensure that You have obtained any and all relevant Planning permissions and building regulations approval, including the submission of any calculations required for Building Regulations approval, BEFORE  You Order Your Goods. We will then manufacture to Your specifications.

    (b) We are not liable for any infringement of Planning laws or Building Regulations and We do not offer any form of advice..

19. INSTALLATION

20. (a) If You have booked other trades or works (electricians, plumbers, landscapers etc) to tie in with the installation, We will not be liable for any extra costs You may incur should the installation be longer or shorter than anticipated. If You employ other contractors (plumbers, electricians, etc) to work alongside the installers whilst the building is being built and they delay the installers, the installers will charge You for their lost time.

    (b) We will advise You if there will be a manufacturing delay for Your replacement Goods/Parts. You can ask for a refund if the delay would inconvenience You and We will collect the goods at no cost to you. Should You choose to wait for replacement Goods/Parts, We will not pay any compensation against any claim for Your lost time, nor against any claim for cancellation of independent contractors that You may employed and pre-booked. 

Phone 01403 888222 / 01293 822722